HomeMy WebLinkAbout1986 Special Provisions Project Agate StCOPY N0.
CITY OF BAKERSFIELD
CALIFOR^1IP,
SPECIFICATIONS
INFORMATION TO BIDDERS
SPECIAL PROVISIONS
BID PROPOSAL
FOR
TRAFFIC SIGNAL SYSTEM ON
AGATE STREET/CASTRO LANE AT
WILSON ROAD
SEPTEMBER, 1986
DEPARTMENT OF PUBLIC WORKS
CITY OF BAKERSFIELD, CALIFORNIA
1501 TRUXTUN AVENUE
BAKERSFIELD. CALIFORNIA 93301
CITY OF BAKERSFIELD
DEPARTMENT OF PUBLIC WORKS
NOTICE TO CONTRACTORS
SEALED PROPOSALS will be received by the City of Bakersfield at the
Office of the Purchasing Officer, City Hall, 1501 Truxtun Avenue, Bakersfield,
California, until 2:00 0' clock P.M, on nrtnhA 16..,`.~~~.~.eto be publicly opened and read immediately thereafter, for the following work:
TRAFFIC SLGNAL SYSTEM ON
AGATE STREET/CASTRO LANE AT
WILSON ROAD
Plans and specifications, and forms of proposal, bonds, and contract,.
may be obtained at the office of the Purchasing Officer by posting a refundable
deposit of ZERO -0- ) for each complete set. Refund of
deposit will be made provided the plans and specifications are returned to the Purchasing .Officer within ten (10) days from date of contract award and the doc-
uffients are in reasonable good condition. f;
No bid will be considered unless it is made on a proposal form furnished
by the Purchasing Officer, which appears herein immediately following the speci-
fications of the project, and is made in accordance with-the provisions set
forth under Section 2, "Proposal Requirements .and Conditions'' of the Standard
Specifications of the Department of Transportation, Business & Transportation Agency, State of California, under date of-July, 1984. Each bid must be accom-
parried by a proposal guarantee in accordance with the requirements of article
2-1.07 of the said Section 2 of the Standard Specifications.
The City of Bakersfield reserves the right to reject any or all bids.
Bids are required on the entire work described herein.
Substitution of securities for moneys retained to ensure performance shall be permitted pursuant to the provisions and requirements of Government
Code 4590.
The Contractor must possess a valid Class A or a Class C-10 Contractor's
License at the time this contract is awarded.
SPECIFICATIONS: The work embraced herein shall be done in accordance
with the Standard Specifications of the Department of Transportation, Business and Transportation Agency, dated July, 1984, insofar as the same may apply and
in accordance with the following provisions.
1
PROGRESS OF THE WORK AND TIME FOR COMPLETION. Attention is directed to the
provisions of Section 8, Article 8-1.Ob, "Time of Completion" and Article
8-1.07, "Liquidated Damages," of the Standard Specifications, and is specifi-
cally hereby made a part of these special provisions.
The Contractor shall furnish the Engineer with a statement fro the vendor
that the order for the electrical materials required for this contract has been
received and accepted by said vendor, and said statement shall be furnished within fifteen (15) calendar days from the date of the contract. Said statement
shall show the date or dates the electrical materials will be shipped.
The Contractor shall begin work within fifteen (15) calendar days from the
date of the contract and shall diligently prosecute the same to completion,
except for signal and lighting standards and other above ground electrical
equipment if said electrical equipment has not yet been received, before the
expiration of
TWENTY {~0} WORKING DAYS
beginning with the fifteenth (15} day following the date of the contract.
Signal and lighting standards and. other above ground electrical equipment
shall not be erected until all electrical materials are received. Upon receipt.
of said electrical materials, .the Contractor shall complete .all electrical work, including functional tests, before the expiration of
FIFTEEN (15} WORKING-DAYS
from the date all electrical materials are received, but in no case shall the
work be completed later than the expiration of
SEVENTY FIVE (75) DAYS
beginning with the fifteenth (15th) day follo~aing the date of the contract for
said work..
lA
CITY OF BAKERSFIELD, CALIFORNIA
DEPARTMENT OF PUBLIC WORKS
SECTION 1. PROPOSAL REQUIREMENTS
(a) GENERAL INFORMATION. The Purchasing Officer of the City of
Bakersfield, California, will receive at her office, City Hall, in said City,
until 2 o'clock P.M, on October 16. 1986 sealed proposals for
TRAFFIC SIGNAL SYSTEM ON
AGATE STREET/CASTRO LANE AT
WILSON ROAD
(b) PROPOSAL FORM. All proposals must be made upon blank forms to be
obtained from the Purchasing Officer, the form of which .appears. herein immedi-
ately following these specifications. All proposals must give the prices pro-
- posed, both in writing and figures, and must be signed by the bidder, with his-
address. If the proposal is made by an individual, his name and post office
address must be shown. If made by a firm or partnership, the name and post.
office address of each member of the firm or partnership must be shown. If made by a corporation, the proposal must show the names of the st-ate under the
laws of which the corporation was chartered and the names, titles, and busi-
ness addresses of the president, secretary and treasurer.-
(c) BIDDER'S GUARANTEE. All bids shall be presented under sealed
cover and shall be accompanied by a certified check or bid bond made payable
to the City of Bakersfield, for an amount equal to at least ten percent (10%
of the amount of_sad bid, and no bid shall be considered unless such certi- fled check or bid bond is enclosed therewith.
(d) RETURN OF BIDDER'S GUARANTIES. Within ten (lo) days after the
award.: of the contract, the City of Bakersfield will return the proposal
guaranties accompanying such of the proposals as are not to be considered in
making the award.. All other proposal guaranties will be held until the con-
- tract has been finally executed, after. which they will be returned to the respective bidders whose proposals they accompany.
(e) CONTRACT BONDS. The Contractor shall furnish two. good and suffi-
cient bonds. One of the said bonds shall guarantee the faithful performance
of the said contract by the Contractor and shall be in an amount equal to one
hundred percent (100%) of the contract price. The other of the said .bonds
shall. be in an amount of fifty percent (50%) of the contract price and shall
be furnished as required by the terms of an act entitled:
"An act to secure the payment of the claims of persons employed
by contractors upon public works, and the claims of persons who
furnish materials, supplies, teams, implements, or machinery used
or consumed by such contractors in the performance of such works,
and prescribing the duties of certain public officers with respect
thereto," approved May 10, 1919, as amended.
Forms of bonds required may be obtained at the office of the City
Attorney.
2
Whenever any surety or sureties on any such bonds, or on any bonds
required by law for the protection of the claims of laborers and material men,
become insufficient, or the Mayor has cause to believe that such surety or sure-
ties have become insufficient, a demand in writing may be made of the Contractor
for such further bond or bonds or additional surety, not exceeding that origi-
nally required, as is considered necessary, considering the extent of the work remaining to be done. Thereafter no payment shall be made upon such contract to
the Contractor or any assignee of the Contractor until such further bond or
bonds or additional surety has been furnished.
(f) REJECTION OF PROPOSALS CONTAINING ALTERATIONS, ERASURES OR
IRREGULARITIES. Proposals may be rejected if they show any alterations of form,
additions not called for, conditional or alternative bids, incomplete bids, era-
sures or irregularities of any kind. .Proposals in which the prices obviously are unbalanced may be rejected.
The right is reserved to .reject any and all proposals..
(g) ,AWARD OF CONTRACT. The award. of the contract, if it be awarded,
will be-made within thirty (30) days after the opening of the proposals.
(h) EXECUTION OF CONTRACT. The contract shall be signed by the suc-
cessful bidder and returned, together with the contract bonds within ten (10) days, not including Sundays, after the bid-der has received notice that the con-
tract has been awarded. No proposal shall be considered binding upon the City
until the execution of the contract. All contracts shall be considered as being
made and entered into in the City of Bakersfield, California.
Failure.. to execute a contract and file acceptable bonds as provided
herein within ten (14) days, not. including Sundays, after the bidder has received notice that the contract has been awarded, shall be just cause for the
cancellation of the award and the forfeiture of the proposal guaranty.
(i) EXAMINATIONS OF PLANS, SPECIFICATIONS, SPECIAL PR0vISI0NS, AND.
SITE OF WORK. The bidder is required to examine carefully the site of, the pro°
posal, plans and specifications, and contract forms for the work contemplated,
and i~ will be assumed that the bidder has investigated and is satisfied as to
the conditions to be encountered, as to the character, quality, and quantities of work to be ,performed ,and materials to be furnished, and as to the require-
meats of the specifications, the special provisions, and the contract.. It is
mutually agreed that the submission of a proposal shall be considered prima
facie evidence that the bidder has made such examination.
3
SECTION 2, SCOPE OF WORK
e
(a) WORK TO BE DONE. The work to be done consists of furnishing all
labor, materials, methods and processes, implements, tools and machinery, except as otherwise specified, which are necessary and required to construct the pro-
posed improvements, as designated in the contract.
(b) ALTERATIONS. By mutual consent in writing of the parties signa-
tory to the contract, alterations or deviation, increases or decreases, addi-
tions or omissions, in the plans and specifications, may be made and the same
shall in no way affect or make void the contract.
The City of Bakersfield reserves the right to increase or decrease the.
quantity of any item or portion of the work, or to omit portions of the work as
may be deemed- necessary or expedient by the Engineer.
(c) EXTRA WORK. New and unforeseen work will be classed as extra
work when such work cannot be covered by any of the various items or combination
of items for which there is a bid price.
The contractor shall do no extra work except upon written order form
the Engineer. For such extra work the contractor shall receive payment as pre-
viously agreed upon in writing, or he shall be paid on force account.
(d) REMOVAL OF ,OBSTRUCTIONS. The contractor shall remove and dispose
of all structures, debris, or other obstructions or any character of the con-
struction of the. street or road, if and as required by the Engineer.
,The contractor shall remove and dispose of all trees designated by the
Engineer as obstructions to the proper completion of the: work.
The removing and disposing of all. obstruct-ions to the prosecution of
the contract, unless otherwise- specified, shall be considered as included in the
various items of contract work and no additional compensation will be allowed
therefor.
(e) FINAL CLEANING UP. Upon completion and before making application
for acceptance of the work, the. contractor shall clean the street or road, bor-
row pits, and all ground occupied by him in connection with the work, of all
rubbish, excess materials, temporary structures, and equipment; and all parts of
the work shall be left. in a neat and presentable condition.
4
SECTION 3, CONTROL OF THE WORK
(a) AUTHORITY OF THE ENGINEER. The engineer shall decide any and all questions which may arise as to the quality or acceptability of materials fur-
nished and work performed, and as to the manner of performance and rate of pro-
gress of the work; all questions which arise as to the interpretation of the
plans and specifications; all questions as to the acceptable fulfillment of the
contract on the part of the contractor; and all questions as to claims and
compensation..
The Engineer's decision shall be final and he shall have executive authority to enforce and make effective such decisions and orders as the con-
, tractor fails to carry out promptly.
(b) PLANS. All authorized alterations affecting the requirements and
information given on the approved plans shall be in writing. No changes shall
be made of any plan or drawing after the same has been approved by the Engineer,
except by direction of the Engineer.
Working drawings or plans for any structure not included in the plans furnished by the Engineer shall be approved by the Engineer before any work
involving these plans shall be performed, unless approval is waived in writing
by the Engineer.
It is mutually agreed, however, that the approval by the Engineer of
the contractor's working plan does not relieve the contractor of any responsibility
for accuracy of dimension`s and details, and that the contractor shall be respon- Bible for agreement and conformity of his working plans with the approved plans
and specifications.
(c) CONFORMITY WITH PLANS AND ALLOWABLE DEVIATION, Finished surfaces
in all cases shall conform with the lines, grades, cross-sections, and dmen-
sions shown on the approved plans. Deviations from the approved plans, as may..
be required by the exigencies of constru-coon will be determined in all cases by
the Engineer and authorized in writing.
(d) COORDINATION OF PLANS, SPECIFICATIONS, AND SPECIAL PROVISIONS.
These specifications, the plans, special provisions, and all supplementary docu-
m~nts are essential parts of the contract, and a requirement occurring in one is
a binding as though occuring in all. They are intended to be cooperative, to
describe, and to provide for a complete work. Plans shall govern over specifi-
cations; special provisions shall govern over both specifications and plans.
City specifications shall govern over State Standard Specifications.
(e) INTERPRETATION OF PLANS AND SPECIFICATIONS. Should it appear
that the work to be done, or any matter relative thereto, is not sufficiently
detailed or explained in these specifications, plans, and the special provision,
the contractor shall apply to the Engineer for such further explanations as
may be necessary, and shall conform to such explanation or interpretation as
part of the contract, so far as may be consistent with the intent of .the origi-
nal specifications. In the event of doubt or question relative to the true meaning of the specifications, reference shall be made to the City Council,
whose decision thereon shall be final.
5
In the event of any discrepancy between any drawings and the figures
written thereon, the figures shall be taken as correct.
(f) SUPERINTENDENCE. Whenever the contractor is not present on any
part of the work where it may be desired to give direction, orders will be
given by the Engineer in writing, and shall be received and obeyed by the super- intendent or foreman in charge of the particular work in reference to which
orders are given.
(g) LINES AND GRADES. All distances and measurements are given and
will be made in a horizontal plane. Grades are given from the top of stakes or
nails, unless otherwise noted on the plans.
Three consecutive points shown on the same rate of slope must be used in common, in order to detect any variation from a straight grade, and in case
any such discrepancy exists, it must be reported to the Engineer. If such a
discrepancy is not reported to the Engineer, the contractor shall be responsible
for any error in the finished work.
The contractor shall give at least 24 hours notice in writing when he
will require the services of the Engineer for laying out. any portion of the
work.. The contractor shall furnish the Engineer such facilities and labor, nec-
essary for making and maintaining points and lines, as he may require. Labor furnished by the Contractor for such purposes will be paid. for as Extra Work.
The contractor shall preserve all stakes and points set for lines,
grades, or measurements of the work in their proper places until authorized to
remove .them by the Engineer. All expenses incurred in replacing stakes that
have been removed without proper authority shall be paid by the contractor.
(h} INSPECTION. The Engineer shall at all times have access to the work dux°ing construction, and shall be furnished with every reasonable facility
for discertainng full knowledge respecting the progress, workmanship, and char-
acter of materials. used and employed in the work.
Whenever the contractor varies the period during which work is carried
on each day, he shall give due notice to the Engineer, so that proper inspection
may be provided. Any work done in the absence of the Engineer will. be subject to ~e j ection.
The inspection of the work shall. not relieve the contractor of any of
his obligations to fulfill the contract as prescribed. Defective work shall be
made good, and unsuitable materials may be rejected, notwithstanding the fac t
that such defective work and unsuitable materials have been previously over-
looked by the Engineer and accepted or estimated for payment.
Projects financed in whole or in part with State funds shall be sub-
, ject to inspection at all times by the Director of Public Works, or his agents,
(i) REMOVAL OF DEFECTIVE AND UNAUTHORIZED WORK. All work which is
defective in its construction or deficient in any of the requirements of these
specifications shall be remedied, or removed and replaced by the contractor in
an acceptable manner, and no compensation will be allowed for such correction.
6
Any work done beyond the lines and grades shown on the plans or estab-
lisped by the Engineer, or any extra work done without written authority, will
be considered as unauthorized and will not be paid for.
Upon failure on the part of the contractor to comply forthwith with
any order of the Engineer made under the provisions of this article, the Engineer shall have authority to cause defective work to be remedied, or removed
and replaced, and unauthorized work to be removed, and to deduct the costs
thereof from any monies due or to become due the contractor.
(j) FINAL INSPECTION,. Whenever the work provided and contemplated by
the contract shall have been satisfactorily completed and the final cleaning up
performed, the Engineer will make final inspection.
SECTION 4. CONTROL OF MATERIALS
(a) SAMPLES AND TESTS. At the option of the Engineer, the source of
supply of each of the materials shall be approved by the Engineer before deliv-
ery is started and before such material is used in the work. Representative
preliminary samples of the character and quality prescribed shall be submitted
by the contractor or producer of all materials to be used in the work, for test- ing or examination as desired by the. Engineer.
All tests of materials furnished by the contractor shall be made in
accordance with commonly recognized standards of national organizations, and
such. special methods and tests as are prescribed in the specifications.
The contractor 'shall furnish such samples of materials as are
requested by the Engineer, without charge. No material shall be used until it has been approved by the Engineer. Samples will be secured and tested whenever
necessary to determine the quality of material.
(b) DEFECTIVE MATERIALS. All materials non conforming to the
requirements of these specifications shall be considered as defective, and all
such .:materials, whether in place or .not, shall be rejected and shall be removed
immediately from the site of the work unless otherwise permitted by the
Engineer. No rejected material, the defects of which-have. been subsequently corrected, shall be used until approved in writing by the Engineer.
Upon failure on the part of the contractor to comply with any order of
the Engineer made under the provisions of this article, the Engineer shall have
authority to remove and replace. defective material and to deduct the cost of
removal and replacement from any monies due or to become due the contractor.
7
SECTION 5, LEGAL RELATIONS AND RESPONSIBILITIES
TO THE PUB L I C
(a) LAWS TO BE OBSERVED. The contractor shall keep himself fully
informed of all existing and future State and National laws and all municipal ordinances and regulations of the City of Bakersfield which in any manner affect
those engaged or employed in the work, or the materials used in the work, or
which in any way affect the conduct of the work, and of all such orders and
decrees of bodies or tribunals having any jurisdiction or authority over the
same.
(b) HOURS OF LABOR. The contractor shall forfeit, as penalty to the
City of Bakersfield, Ten ,Dollars ($10,00) for each laborer, workman, or mechanic employed in the execution of the contract by him, or by any subcontractor under
him,-upon any of the work hereinbefore mentioned, for each calendar day during.
which said laborer, workman, or mechanic is required or permitted to labor in
violation of the provisions of Section 1810 to Section 1815, inclusive, of the
Labor Code.
(c) The contractor shall comply with Section 6705 of the Labor Code
which provides that the contractor's responsibility shall be as follows:
If the contract price for the project includes an expenditure in
excess of twenty-.five thousand dollars ($25,000) for excavation of any trench or
trenches five feet or more in depth, the contractor or his subcontractor shall
not begin any trench excavation unless a detailed plan, showing the design of
shoring, bracing, sloping or other provisions to be made for-worker protection
during the excavation of the trench, has been. submitted by the contractor to the
City Engineer and the detailed plans has been approved by the City Engineer,
If such plan varies from the shoring system standards established by
the Construction Safety Orders of the Division of Industrial Safety, the plan
shall be prepared by a registered civil or structural engineer.
Nothing in this section shall be deemed to allow the use of a shoring,
sloping, or protective system less effective than that required by the
Construction Safety Orders of the Division of Industrial Safety.
Nothing in this section shall be construed to impose tort liability on
the awarding body or any of its employees.
The terms "public works" and "awarding body", as used in this section,
shall have the same meaning as in Labor Code Sections 1120 and 1122 respectively.
8
(d) EQUAL EMPLOYMENT OPPORTUNITY. During the performance of this
contract the Contractor agrees as follows:
(1) The contractor will not discriminate against any employee
or applicant for employment because of race, creed, color,
sex, or national origin. The Contractor will take affirma-
tive action to ensure that applicants are employed, and that employees are treated during employment, without
regard to their race, creed, color, sex, or national ori-
gin. Such action shall include, but not be limited to, the
following: Employment, upgrading, demotion, or transfer;
recruitment or recruitment advertising; layoff or ter-
urination; rates of pay or of-her forms of compensation; and
selection for training, including apprenticeship. The
Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be
provided setting forth the provisions of this non-
discrimination clause.
(2) The Contractor will, in all solicitations or advertisements
for employees placed by or on .behalf of the Contractor,
state that all qualified applicants will receive considera-
Lion for employment without regard to race, creed, color, sex, or national origin.
(3) The Contractor will send to each labor union or representa-
tive of workers with which he has a collective bargaining
agreement or other contract or understanding, a notice to
be provided advising the labor union or workers' represen-
tative of the Contractor's commitments under Section 202 of
Executive Order No. 11246 of September 24, 1965 and shall post copies of the notice in conspicuous places available
to employees and applicants for employment.
(4) The Contractor will comply with all provisions of Executive
Order No. 11246 as amended by Executive Order 11375, and of
the rules, regulations, and relevant orders of the-
Secretary of Labor.
(e) PREVAILING WAGE. The Contractor shall, as a penalty to the City
of Bakersfield, forfeit $25.00 for each calendar day or portion thereof, for
each workman paid less than the stipulated prevailing rates for such work or
craft in which such workman is employed under this contract or by any subcon-
tractor under him, in violation of the provisions of Section 1710 to Section
1780 , inclusive of the Labor Code .
Copies of the prevailing rate of per diem wages, for each craft, clas- sification or type of w®rkman needed to execute the contract, are on file in the
office of the Director of Public Works and shall be made available. to any inter-
ested party on request..
(f) APPRENTICES. All Contractors and Subcontractors shall comply
with the provisions of Labor Code Section 1771.5 relating to the employment of
apprentices.
9
(g) REGISTRATION OF CONTRACTORS. Before submitting bids, Contractors
shall be licensed in accordance with the provisions of Section 7055 of Business
and Professions Code.
(h) PERMITS AND LICENSES. The Contractor shall procure all permits
and licenses, pay all charges and fees, and give all notices necessary and inci-
dental to the due and lawful prosecution of the work.
(i) PATENTS. The Contractor shall assume all responsibilities aris-
ing from the use of patented materials, equipment, devices, or processes used on
or incorporated in the work.
(j) PUBLIC CONVENIENCE AND SAFETY. The Contractor shall so conduct
his operations as to cause the least possible obstruction and inconvenience to
public traffic. Unless other existing streets are stipulated in the special
provisions to be used as detours, all traffic shall be permitted to pass through the work.
Residents along the road or street-shall be provided passage as far as
practicable. Convenient access to driveways, houses and buildings along the
road or street shall be maintained and temporary crossings shall be provided and
maintained in good condition. Not more than one cross or intersecting street or
road shall be closed at any time without the approval of the Engineer.
The Contractor shall furnish, erect, and maintain such fences,
barriers, lights, and signs as are necessary go give adequate warning to the
public at all times that the improvement is under the construction and of any
dangerous conditions to be encountered as a result thereof, and he shall also
erect and maintain such warnings and directional signs as may be furnished by
the City.
Full compensation for conforming to the provisions of this Section 5 (j) shall be considered as included in the prices paid for the various contract
items of work and no additional compensation will be allowed therefor.
(k) RESPONSIBILITY FOR DAMAGE. The City of Bakersfield, the City
Council, or the Engineer shall not be answerable or accountable in any manner
for any loss or damage that may happen to the work or any,part thereof; or for
any material or equipment used in performing the work, or for injury or damage
to any person or persons, either workmen or the public; or for damage to adjoining property caused by the negligence of Contractor or one of his subcon-
tractors during the progress of the work at any time before final acceptance.
The Contractor shall indemnify and save harmless the City of
Bakersfield, the City Council, and the Engineer from any suits, claims, or
actions brought by any person or persons for or on account of any injuries or
damages. sustained or arising in the construction of the work or in consequence
thereof.
(1) CONTRACTOR'S RESPONSIBILITY FOR WORK. Except as provided above,
until the formal acceptance of the work by the City Engineer, the Contractor shall
have the charge and care thereof and shall bear the risk of injury or damage to any
part thereof by the action of the elements or from any other cause, whether
arising from the execution or from the non-execution of the work. The Contractor
10
shall rebuild, repair, restore, and make good all injuries or damages to any
portion of the work occasioned by and of the above causes before final accep-
tance and shall bear the expense thereof, except such injuries or damages occa-
sioned by acts of the Federal Government or the public enemy.
(m) NO PERSONAL LIABILITY. Neither the City Council, the Engineer,
nor any other officer or authorized assistance or agent shall be personally
responsible for any liability arising under the contract.
(n) RESPONSIBILITY OF CITY. The City of Bakersfield shall not be
held responsible for the care or protection of any material or parts of the
work prior to final acceptance, except as expressly provided in these
specifications.
11
SECTION 6,0 PROSECUTION AND PROGRESS
(a) SUBLETTING AND ASSIGNMENT. The Contractor shall give his per-
sonal attention to the fulfillment of the contract and shall keep the work under
his control.
Subcontractors will not be recognized as such, and all persons engaged
in the work of construction will be considered as employees of the Contractor,
and their work shall be subject to the provisions of the contract and
specifications.
Where a portion of the work sublet by the Contractor is not being pro-
secuted in a manner satisfactory to the City Engineer, the subcontractor shall
be removed immediately on the requisition of the City Engineer and shall not again be employed on the work.
(b) The Contractor shall diligently. prosecute the work to completion
before the expiration of the permitted number of working days or calendar days
as specified on Page 1 of this specification.
(c) CHARACTER OF WORKMEN. If .any subcontractor or person employed by
the. Contractor shall fail or refuse to carry out the directions of the Engineer or shall appear to the Engineer to be incompetent or to act in a disorderly or
improper manner, he shall be discharged immediately on -the requisition of the
.Engineer, and such person shall not again be employed on the work,
(d) TEMPORARY SUSPENSION OF WORK. The Engineer shall have the.
authority to suspend the wark wholly `or in part, for such period as he may deem
necessary, due to unsuitable weather, or to such other conditions as are consid-
ered unfavorable for the suitable prosecution of the work, or for such time. as he may deem necessary, due to the failure on the part of the Contractor to carry.
out orders given, or to perform any provisions of the work. The Contractor
shall immediately obey such order of the Engineer and shall not resume the work
until ordered in writing by the Engineer.
(e) TIME OF COMPLETION AND LIQUIDATED DAMAGES... It is agreed by the
parties to the contract that in .case all the work called for under the contract
is riot completed before or upon the expiration of the time limit as set forth in these .specifications, damage will be sustained by .the City of Bakersfield, and
that it is and will be impracticable to determine the actual damage which the
City will sustain in the event of and by reason of such delay, and it is there-
. fore agreed ,that the Contractor will pay to the City of Bakersfield the sum of
12
Two Hundred Dollars ($200.00) per day for each and every calendar day's delay
beyond the time prescribed to complete the work; and the Contractor agrees to
pay such liquidated damages as herein provided, and in case the same are not
paid, agrees that the City of Bakersfield may deduct the amount thereof from any
money due or that may become due the Contractor under the contract.
It is further agreed that in case the work called for under the con-
tract is not finished and completed in all parts and requirements within the
tiffie specified the City Council shall have the right to extend the time for com-
pletion or not, as may seem best to serve the interest of the City; and if it
decides to extend the time limit for the completion of the contract, it. shall
further have the right to charge to the Contractor, his heirs, assigns or sure-
ties, and to deduct from the final payment for the work, all or any part, as it
may deem proper, of the actual cost of engineering, inspection, superintendence, and other. overhead expenses which are directly chargeable to the contract, and
which accrue during the period of such extension, except that the cost of final
surveys. and preparation of final estimate shall not be included in such charges.
The Contractor shall not be assessed with liquidated damages nor the
cost of engineering and inspection during any delay in the completion of the
work caused by acts of God or of the public enemy, acts of the City, fire,
floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unu- sually severe weather or delays of subcontractors due to such causes; provided
that the Contractor shall within ten (10) days from the beginning of any such
delay, notify the Engineer in writing of the causes of delay, who shall ascer-
tarn the facts and the extent of the delay, and his findings of the facts
thereon shall be final and conclusive.
(f~ SUSPENSION'OF CONTRACT. If at any time in the opinion of the
City Council, the Contractor has failed to .supply an adequate working force, or material of proper quality, or has failed in any other respect to prosecute
the work with the diligence and force specified and intended in and by the
terms of the contract, notice thereof in writing will be served upon him,
and should he neglect or refuse to provide means for a satisfactory
compliance with the contract, as directed by the Engineer, within the time
specified in such notice, the City Council in any such case shall have the
power to suspend the operation of the contract. Upon receiving notice of such
suspension, the Contractor shall discontinue said work, or such parts of it as the City Council may designate. Upon such suspension, the Contractor's control
shall .terminate, and thereupon the City Council, or its duly authorized
representative, may take possession of .all or any part of the Contractor's
materials, tools, equipment, and appliances upon the premises, and use the same
for the purpose of completing said contract, and hire such force and buy or rent
such additional machinery, tools, appliances and equipment, and buy such
additional materials and supplies at the Contractor's expense as may be
necessary for the proper conduct of the work and for the completion thereof; or may .employ other parties to carry the contract to completion, employ the neces-
sary workmen, substitute other machinery or materials, and purchase the materi-
als contracted for, in such .manner as the City Council may deem proper; or the
City Council may annul and cancel the contract and re-let the work or-any part
thereof. Any excess of cost arising therefrom over and above the contract price
.will be charged against the Contractor and his sureties, who will be liable
13
therefor. In the event of such suspension, all money due the Contractor or
retained under the terms of this contract shall be forfeited to the City; but
such forfeiture will not release the contractor or his sureties from liability
or failure to fulfill the contract. The Contractor and his sureties will be
credited with the amount of money so forfeited toward any excess of cost over
and above the contract price, arising from the suspension of the operations of
the contract and the completion of the work by the City as above provided, and the Contractor will be so credited with any surplus remaining after all just
elaims for such completion have been paid.
In the determination of the question whether there has been any such
non-compliance with the contract as to warrant the suspension or annulment
thereof, the decision of the City Council shall be binding on all parties to the
contract.
(g} RIGHT OF WAY. The right of way for the work to be constructed
will be provided by the City. The Contractor shall make .his own arrangements,
and pay all expenses for additional area required by him outside of the limits
of right of way unless otherwise provided in the Special Provisions.
14
Section 7, MEASUREMENT AND PAYMENT
(a) EXTRA AND FORCE ACCOUNT WORK. Extra work as hereinbefore
defined, when ordered and accepted, shall be paid for under a written work order
in accordance with the terms therein provided. Payment for extra work will be made at the unit price or lump sum previously agreed upon by the Contractor and
the Engineer, or by force account.
If the work is done on force account the Contractor shall receive the
actual cost of all material furnished by him as shown by his paid vouchers, plus
fifteen percent (15%), .and for all equipment and teams that are necessary he
shall receive the current prices in the locality, which shall have been previ-
ously determined and agreed to in writing by the Engineer and by the Contractor, plus fifteen percent (15%) and for all labor that is necessary he shall receive
the current prices in the locality, plus twenty percent (20%) provided, however,
that the city reserves the right to furnish such materials required as it deems
expedient, and the Contractor shall have no claim for profit on the cost of such
materials. The price paid for labor shall include all payments imposed by State
and Federal laws for all payments made to, or on behalf of, the workmen, other
than actual wages.
All extra work and force account shall be adjusted daily upon report sheets, prepared by the Engineer, furnished to the Contractor and signed by .both
parties, which daily reports. shall thereafter be considered the true record of
extra work or force account work done.
(b) PROGRESS PAYMENTS. The Contractor shall, once in each month,
submit for approval, an estimate in writing to the City Engineer of the total
.amount of work done by the Contractor, to the time of such estimate, and the
value thereof, The City of Bakersfield shall retain ten percent (10%) of such estimated value of the work done as part security for the fulfillment of the
contract by the Contractor., and shall monthly pay to the Contractor, while
.carrying on the work, the balance not retained, as aforesaid, after
deducting therefrom all previous payments and all sums to be kept or
retained under the provisions of the contract. No such estimate or
payment shall be required to be made, when in the judgment of the City Engineer
the work is not proceeding in accordance with the provisions of the contract, or when in his judgment the total value of the work done since the last estimate
affiounts to less than Three Hundred Dollars ($300,00).
(c) FINAL PAYMENT. The City Engineer shall, after the completion of
the contract, make a final estimate of the amount of work done thereunder, and
the value of such work, and the City of Bakersfield shall pay the entire sum so
found to be due after deducting therefrom all previous payments and all amounts to
be kept and all amounts to be retained under the provisions of the contract. All prior partial estimates and payments shall be subject to correction in the
final estimate and payment. The final payment shall not be due and payable
until the expiration of thirty (30) days from the date of acceptance of the work
by the City Council.
It is mutually agreed between the parties to the contract that no cer-
tificate given or payments made under the contract, except the final certificate
or final payment, shall be conclusive evidence of the performance of the contract, either wholly or in part, against any claim of the party of the first
part,. and no payment shall be construed to be an acceptance of any defective
work or improper materials.
15
And the Contractor further agrees that the payment of the final amount
due under the contract, and the adjustment and payment for any work done in
accordance with any alterations of the same, shall release the City of
Bakersfield, the City Council, and the Engineer from any and all claims or lia- bility on account of work performed under the contract or any alteration
thereof.
(d) SUBSTITUTION OF SECURITIES. Whenever herein provision is made for
withholding or retention of moneys to ensure performance, substitution of an
equivalent amount (value) of securities shall be permitted in accordance with
the provisions and requirements of Government Code Section 4590.
SECTION S. PROVISIONS OF STANDARD SPECIFICATIONS
This work embraced herein shall be done in accordance with the appropri-
ate provisions of construction details, Section 10 to Section 95, "inclusive, of
the .Specifications entitled "State of California, Department of Transportation,
Standard Specifications, July, 1984," insofar as the same may apply, which spec-
. ifications are hereinafter referred to as the Standard Specifications, and. in
accordance with the following special provisions.
Whenever in the Standard Specifications the following terms are .used,
they shall be understood to mean and refer to the following:
Department of Transportation, CALTRANS - The Engineering Department of
the City of Bakersfield.
Director of Public Works City Engineer, City of Bakersfield.
Engineer - The City Engineer, acting either directly or through properly
authorized agents, such agents acting within the scope of the particular duties
entrusted to them.
Laboratory - The designated laboratory ,authorized by the City of
Bakersfield to test materials and work involved in the contract.
State - The City of Bakersfield.
Other terms appearing in the Standard Specifications, the general provi-
sions, and the special provisions, shall have -the intent and meaning specified
in Section 1, Definition of Terms of the Standard Specifications..
In the event that any portion of the Standard Specifications incorporated
herein shall conflict with any of the provisions delineated in the special pro- visions section herein set forth, the provisions so delineated shall take piece-
den~e over and shall be used in lieu of such conflicting portions of the
Standard Specifications.
lb
SECTION 9. INSURANCE
In addition to any other form of insurance or bonds required under the
terms of the contract and specifications, the Contractor will be required to
carry insurance of the following kinds and amounts: contractor's public liabil- ity insurance policy for property damage, personal injury. and automobile liabil-
ity (with an insurance company licensed to do business in the State of
California) in an amount not less than FIVE HUNDRED THOUSAND DOLLARS ($500,000),
combined single-limit coverage with a TWO MILLION DOLLAR ($2,000,000.00)
umbrella policy (containing a drop down provision) or, in lieu thereof, a 2.5
MILLION DOLLAR combined single-limit policy. The City of Bakersfield, its
mayor,. council, officers, agents and employees shall be named as additional
insureds under the policy which shall operate as primary insurance.
If any part of the work is sublet, similar insurance shall be provided
by or in behalf of-the subcontractors to cover their operations.
The insurance hereinbefore specified shall be carried until all work
required to be performed under the terms of the contract is satisfactorily com-
pleted as evidenced by the formal acceptance by the City.
The Contractor shall furnish the Finance Department with one (1) certif- icate copy of each of the executed policies or a certified Certificate of
Insurance .
The certification on such policies shall guarantee that the policy will
not be amended, altered, modified, or canceled in so far as the coverage contem-
plated hereunder is concerned, without at least five (5) days' notice mailed by
registered mail to the Finance Department, City. of Bakersfield, Bakersfield,
California.
The insurance herein required shall be obtained by the successful bidder
and the certified copy of the policies or Certificate of Insurance furnished as
herein provided, within the time fixed herein for his execution of the contract,
Full compensation for all premiums which the Contractor and the subcon-
tractors are required to pay on all the insurance described above shall be con- sidered as included in the prices paid for the various items of work to be
performed under the contract, and no additional allowance will be made therefor
or for additional premiums which may be required by extension of the policies of
e insurance.
17
SECTION 10. QUANTITIES
The following preliminary estimate of the quantities of work to be
done and materials to be furnished are approximate only, being given as a basis
for the comparison of bids, and the City of Bakersfield does not expressly or by
implication agree that the actual amount of work will correspond therewith, but reserves the right to increase or decrease the amount of any class or portion of
the work or to omit portions of the work that may be deemed necessary or expedi-
ent by the Engineer.
The provisions of Section 4-1.03B of the Standard Specifications
relative to alterations not involving changes in the character of the work shall
not apply to any contract item of work in this proposal.
ENGINEER'S ESTIMATE
ITEM QUANTITY UNIT DESCRIPTION
1, Lump Sum L.S. Signals and lighting.
2. 6 Each Install signs tmast arm hanger, street name sign).
SECTION 11, MATERIALS
The City o~f Bakersfield shall furnish the controllers and cabinet
assemblies, signal standards, and street name sign panels.
The Contractor shall furnish, for use under these special provisions,
all other materials required to complete the attached contract,
City furnished materials shall be-made available to the Contractor at
the City Corporation Yard, 4101 Truxtun Avenue.
SECTION 12. DESCRIPTION OF WORK
The work to be done consists, in general,. of installing signs, traffic
signals and lighting.
Such other items or details, not mentioned above, that are .required by
the plans, Standard Specificat-ions, or these special provisions shall be per-
. formed, placed, constructed or installed.
Said work to be done is specifically shown, marked and detailed upon a
Plan entitled:
TRAFFIC SIGNAL SYSTEM ON
AGATE STREET/CASTRO LANE AT
WILSON ROAD
13
SECTION 13. GENERAL PROVISIONS.
(a) PUBLIC SAFETY AND PRESERVATION OF PROPERTY. Attention is directed
to Section 7 of the Standard Specifications. The Contractor shall comply with
the provisions of this section, except as otherwise directed by the Engineer.
Such provisions for public safety shall meet the minimum requirements
and shall be subject to the approval of the City Engineer.
Full compensation for complying with the requirements of this section
shall be considered as included in the contract prices paid for the various
items of work and no additional compensation will be allowed therefor.
(b) OBSTRUCTIONS. Attention is directed to Section 8-1.10, "Utility
and Non-Highway Facilities," of the Standard Specifications, the plans, and the
especial provisions. Where extra work is required by said section it shall be
paid for as provided in Section 7.(a) of these specificationse
The Contractor will be required to work around public utility facilities
and other improvements that are to remain in place within the construction area
or that are to be relocated and relocation operations have not been completed. In accordance with the provisions of Section 7-1.11, "Preservation of Property,"
and 7°1.12, "Responsibility for Damage," of the Standard Specifications, the
Contractor will be liable to owners of such facilities and improvements for any
damage or interference with service resulting from conducting his operations.
The exact location of underground facilities and improvements within the con-
struction area shall be ascertained by the Contractor before using equipment
that may damage such facilities or interfere with the services. Other forces may be engaged in moving br removing utility facilities or other improvements or
maintaining services or utilities. The Contractor shall cooperate with such
forces and conduct his operations in such a manner as to avoid any unnecessary
delay or hindrance to the work being performed by other such forces.
Any-delay to the Contractor due to utility relocation whether or not the
utility is shown or correctly located on the plans will not be compensated for
as idle time. However, additional contract time co~unensurate with such delays may be allowed.
At .locations where irrigation systems exist, the Engineer will direct
the Contractor as to what steps will be required to protect the irrigation sys-
tem ar~d the area it serves. The. Contractor shall replace the irrigation system
as directed by the Engineer.
Existing land subdivision monuments and stakes shall be fully protected from damage or displacement and they shall not be disturbed unless directed by
the Engineer.
Attention is directed to the fact that nuisance water may be present at
all times along the project. It will be the responsibility of the Contractor to
provide for handling of said water and any expense involved shall be considered
as included in the prices paid for the various items of work and no additional
allowance will be made therefor.
Except in the case of extra work, full compensation for conforming to
the requirements of this article shall be considered as included in the prices
paid for the various items of work and no additional com ensation will be made
P therefor.
19
(c) OMISSIONS IN SPECIFICATIONS AND DRAWINGS. Any materials or work
mentioned in the specifications and not shown on the drawings or shown on the
drawings and not mentioned in the specifications shall be of the same effect as
if shown or mentioned in both.
Omissions from the drawings or the specifications of the materials or details of work which are manifestly or obviously necessary to carry out the
intent of the drawings and specifications or which are customarily furnished or
performed, shall not relieve the Contractor of his responsibility for furnishing
such omitted materials or performing such omitted work; but shall be furnished
or performed as if fully shown or described in the drawings or specifications.
(d) MATERIALS. Whenever any material is specified by name and number
thereof, such specifications shall be deemed to be used for the purpose of faci- litating description of the materials and establishing quality, and shall be
deemed and construed to be followed by the words "or approved equal". No sub-
stitution will be permitted other than as described herein unless authorized by
the Engineer before the bids are opened. All materials shall be new .and the
best of their class and kind.
(e) ADJUSTMENT OF OVERHEAD COSTS. The provisions of Section 9-1.08 of
the. Standard Specifications shall not apply to final cost of this contract and no final adjustment for overhead costs will be made.
(f) DUST CONTROL. It shall be the Contractor's responsibility to pre-
vent a dust nuisance from originating from the site of the work as a result of
his operations during the effective period of this contract. Preventative meas°
ures to be taken by the Contractor shall include but shall not be limited to the
following:
1. Water shall be applied to all unpaved areas as required
to prevent the surface from becoming dry enough to
permit dust formation.
2. Paved surfaces over which vehicular traffic is permitted
to travel shall be kept free of dirt.
Temporary suspension of the work, either as a result of order by the Engineer, or as a result of conditions beyond the control of the Contractor
shall not relieve the Contractor from his responsibility for dust control as set
forth herein.
Full compensation for conforming to the requirements of this article
shall be considered as included in the prices paid for the various contract
items of work and no additional compensation will be allowed therefor.
(g) WATERING. Furnishing and applying water shall conform to the pro-
visions of Section 17 of the Standard Specifications, except that full compensa-
tion therefor shall be considered as included in the prices paid for the
various contract items and no separate payment will be made therefor,
20
(h) ALTERATIONS IN QUANTITY OF WORK. The provisions of Section
4-1.03B, 4-1.03B(1), and 4-1.03B(2), of the Standard Specifications relative to
increases or decreases in the quantity of contract item of work when no change
in the character of the work is involved shall not apply to any contract item of
work in this proposal and the City reserves the right to increase or decrease
the quantity of any item or portion of work as may be deemed necessary or in the best interest of the City.
(i) WORK IN CITY STREETS. All of the work shown on the plans and
included in these specifications that is located in the public streets in the
City of Bakersfield shall be done in accordance with City Ordinances regulating
the use of public streets within the City, except as otherwise provided herein.
The Contractor shall inform himself as to all regulations and require- menu of the City Engineer and Superintendent of Streets of the City of
Bakersfield and shall conduct his operations in compliance therewith.
(j) PERMITS AND LICENSES, The Contractor shall procure all permits
and. licenses, pay all charges and fees and give all notices necessary and inci-
dental to the due and lawful prosecution of the work.
(k) MAINTAINING TRAFFIC. Attention is directed to Sections 7-1.08, "Public Convenience," 7-1.09, "Public Safety," 7-1.092, "Lane Closure," and.
7-1.093, "Portable Delineators," of the Standard Specifications. The Contractor
shall comply with the provisions of these sections and these special provisions.
The Contractor shall furnish, install and maintain signs, lights,
flags and other warning and safety devices when performing work which interferes
a with or endangers the safe movement of traffic on any street or highway.
Signs, lights, flags and other warning and safety devices and their
use shall conform to the requirements set forth in the current "Manual of
Traffic Controls - Warning Signs, Lights, and Devices for Use in Performance of
Work Upon Highways," published by the State of California, Department of
Transportat-ion. Application and use of devices shall be as specified and as
directed by the Engineer.
The Contractor shall keep the Bakersfield Fire Department informed at all times as to the exact location and progress of the work and shall notify
.them immediately of any streets impassable for fire fighting equipment.
The full width of the traveled way shall be open for use by public
traffic on Saturdays, Sundays and designated legal holidays, before 8:30 A.M.
and after 4:00 P.M. on weekdays, and when construction operations are not acti-
vely in progress.
Designated legal holidays are: January 1st, the third Monday in
February, the last Monday in May, July 4th, the first Monday in September,
November 11th, Thanksgiving Day, and December 25th. When a designated legal
holiday falls on a Sunday, the following Monday shall be a designated legal
holiday. when November 11th falls on a Saturday, the preceding Friday shall be
a designated legal holiday.
21
Personal vehicles of the Contractor's employees shall not be parked on
the roadway at any time, including any section closed to public traffic.
When entering or leaving roadways carrying public traffic, the
Contractor's equipment, whether empty or loaded, shall in all cases yield to
public traffic.
The provisions in this section may be modified or altered if, in the
opinion of the Engineer, public traffic will be better served and work expe-
dited. Said modifications or alterations shall not be adopted until approved in
writing by the Engineer,
The prices paid for the various .contract items of work shall be con-
sidered as full compensation for complying with the provisions of this Section 13(k) Maintaining Traffic, and no additional payment will be made therefor.
(1) ORDER OF WORK. Order of work shall conform to the provisions in
Section 5-1.05, "Order of Work," of the Standard Specifications and these spe-
cial provisions.
Prior to commencement of the traffic signal functional tests, all
items of work related to the signal control shall be completed and all signs shall be in place.
(m) COOPERATIONS. The Contractors shall cooperate fully with the
other Contractors performing work on_the site.
Lt is not anticipated that the work to be done by others .will Seri-
. ously delay the Contractof's completion of the work. However, if such work does
result in extraordinary delay, the Contractor may seek relief from. liquidated damages as setaforth_in the fourth paragraph of Article b(e) of these Special.
Provisions.
Full compensation for complying with the requirements of this Article
13(m) shall be considered as included in the prices paid for the various con-
tract items of work and no additional allowance will be made therefor.
22
SECTION 14. SPECIAL PROVISIONS - TRAFFIC SIGNALS AND STREET LIGHTING
(a) DESCRIPTION. Furnishing, installing and modifying traffic sig-
nals and highway lighting and payment therefor shall conform to the provisions
in Section 86, "Signals and Lighting", of the Standard Specifications and these
special provisions,
Traffic signal work is to be performed at the following locations:
AGATE STREET/CASTRO LANE AT
WILSON ROAD
(b) REMOVING AND REPLACING IMPROVEMENTS. Removing and replacing
.improvements shall conform to the provisions in Section 86-2...02, "Removing and
Replacing Improvements," of the Standard Specifications and these special provisions.
(c) FOUNDATIONS. Foundations shall conform. to the provisions in
Section 86-2.0.3, "Foundations," of the Standard. Specifications and these special
provisions.
The Contractor shall furnish the anchor bolts, nuts and washers to be
used for new foundations and shall furnish the appropriate nuts and washers for existing foundations to be reused.
Partland cement concrete shall conform to Section 90-10, "Minor
Concrete," of the Standard Specifications and shall contain not less than 470
° ~ pounds of cement.per cubic yard, except for pile foundations shall contain not
less than 5b4 pounds of cement per cubic yard.
(d} CONDUIT. Conduit shall conform to-the provisions in Section 86-2.05, ".Conduit," of the Standard Specifications and these special provisions.
Insulated bonding bushings will be required on metal conduit.
(e) PULL BOXES. Pull. boxes shall conform to the provisions in
Section 8b-2.06, "Pull Boxes," of the Standard Specifications and these special
provisions.
Recesses for suspension of ballasts will not be required.
23
(f) CONDUCTORS AND WIRING.Conductors and wiring shall conform to
the provisions in Section 8b-2.08, "Conductors," and Section 86-2.09, "Wiring,"
of the Standard Specifications and these special provisions.
Conductors shall be spliced by the use of "C" shaped compression con-
nectors as shown on standard plan ES 13.
Splices shall be insulated by ''Method B."
Numbered sentence 2 in the first paragraph of Section 86-2.09D,
"Splicing," is amended to read.: ,
2. Pedestrian pushbutton commons in pull boxes,
(g) BONDING AND GR4UNDING.~ Bonding aid gr~®~unding shall conform to
the pr..ovisions in section 8~6-2:,10 "Bonding and Grounding," of the Standard Specifications and these special provisions.
(h) SERVICE. S~xvice shall.conform to the provisions-in Section
86-2.11, "service," of the'~Standard Specifications and these special .provisions.
The Engineer wild arrange wi_th_ .the serving , utilit:~ toA: complete service
connections to service points shown.o~ the plans and will pay all required costs
and fees required by the utility.
(i) TESTING.;, T~sjting shall conform to the provisions in Section
. 86-2.14, "Testing," of`th~~Standard Specifications and hese special provisions.
( j ) SIGNAL. FACES, A~1D SIGNAL HEADS. Signal faces..:, signal heads and z.
auxiliary equipment, as s~own,:on the plans, and the installation thereof, shall
conform to the provisions Section 8b-4.01, "Vehicle Signal Faces," 8b-4.02,
"Directional Louvers," 86-~~.Q~, "Backplates10 and 86-4.Ob, "Signaa Mounting Assemblies.," of the Standard~~Specifications and these special provisions.
T,,
Housing, visors, directional louvers and backplates shall not be
structural plastic.
.All lamps for traffic signal units shall be furnished by the
Contractor.
All signal faces shall be provided with 12-inch sections.
(k) PEDESTRIAN SIGNALS. Pedestrian signals shall conform to the pro-
visions in Section 86-4.05, "Pedestrian Signal Faces," of the Standard
Specifications and these special provisions.
Pedestrian signals shall be Type C.
24
{1) LUMINAIRES. Luminaires shall conform to the provisions in
Section 86-b,01, "High Intensity-Discharge Luminaires," of the Standard
Specifications and these special provisions.
Luminaires shall be furnished with 200-watt high pressure sodium lamps
and integral ballasts.
{m} PHOTOELECTRIC CONTROLS. Photoelectric controls shall conform to
the provisions in Section 86-b,07, "Photoelectric Controls", of the Standard
Specifications and these special provisions.
Each luminaire shall be provided with a Type IV photoelectrical
control.
{n) CONTROLLERS, CABINETS AND AUXILIARY EQUIPMENT. The City will furnish the controller and cabinet assembly for each location.
(o) DETECTORS. Detectors shall conform to the provisions in Section
$6-5, "Detectors," of the Standard Specifications and these special provisions.
In lieu of sealing methods specified in Section 86-S.OlA(5),
"Installation Details," of the Standard Specifications, the Contractor may seal
loops in A.C. in accordance with the following:
After conductors are installed ~in the slots cut in the pavement,
the slots shall be filled with asphaltic emulsion Type CSS-1, Section
94, "Asphaltic Emulsion," to within 1/8 inch of the pavement surface.
The emulsion shall be at least 1/2 inch thick above the-.top conductor
- in the sawcut. Plant mixed RMAS, composed of 4 to 8% MC-800 .conform-
ing to Section 93, "Liquid Asphalts," and aggregate of Type 'C', No. 4
max, grading, conforming to Section 39, "Asphalt Concrete," shall be mixed with asphaltic emulsion placed in the slots and tamped, all as
directed by the Engineer. Surplus materials shall be removed from the
adjacent surfaces without the use of solvents. Asphaltic emulsion-
shall be applied to the filled slot and sand applied to the surface,
all as directed by the Engineer.
Detector loops in concrete pads shall be sealed with epoxy sealant con-
forming to State of California, Department of Transportation Standard Specifications, July, 1984, Section 95-2,09, Epoxy Sealant for inductive loops.
Lead ire cables shall be Type A lead-ins and shall conform to the pro-
visions in Section 86-S.OlA(4}, "Construction Materials", of the Standard
Specifications and these special provisions.
(p) PAYMENT. Payment for signals and lighting shall conform to the
provisions in Section 8b-8, "Payment", of the Standard Specifications and these special provisions.
Full compensation for cast-in-drilled hole concrete pile foundations
shall be considered as included in the contract lump sum price paid for the item
requiring foundations and no separate payment will be made therefor.
25
SECTION 15. SPECIAL PROVISIONS - ROADSIDE SIGNS
(a) ROADSIDE SIGNS. Roadside signs shall conform to the provisions
in Section 56-2, "Roadside Signs,',' of the Standard Specifications and these spe-
cial provisions.
Sign panels shall be furnished by the City.
Mast-arm hangers shall be furnished by the Contractor.
Roadside signs shall be installed by mast-arm hanger methods as shown
on Standard Plan Sheet TS-3, 3A (Street Name Sign), or acceptable equal such as
Hawkins M10J Series swinging sign bracket, with return spring removed.
(b) PAYMENT. Payment per unit for installing sign (Mast-arm Hanger, Street Name Sign) shall conform to the provisions in .Section 56-2.46, "Payment,"
of the Standard Specifications,
SECTION 16. SPECIAL PROVISIONS - GUARANTEE FOR TRAFFIC
SIGNAL AND STREET LIGHTING-
SYSTEMS.
(a) GUARANTEE. The Contractor shall furnish a written guarantee to the city on the form attached, guaranteeing all systems, except traffic signal
lamps, installed under-this contract for a period of one (1) year from the date
of acceptance of the work. The guarantee, properly executed, shall be filed
with the City before notice of completion and final acceptance is made by the
City of the work described on the plans and these special provisions.
(b) .PAYMENT. The. lump sum prices paid for installation of traffic
signal and street lighting systems shall include full compensation for furnish- ing the guarantee as required in this section.
26
~ ~
e
e
' r
/d0,4m~a cor~►nr~rc~a/ ,..4c frcui~ /a~~ ~rn~rr, Po /icy safe/y sockv~ bor „a ~ 1-30 ~n~p ~ po%
cirwit /o~,d c~o~Er,
"'•"~'ainti~h ~ ~a~dvi# hvh
br~alCar (sy~~ra/s,~
0
~ GJ/Idy~fOrf dJ .S~OtuI?~
On 1/9na/~Jl'S ,v,'vs
I•'°6 bars ground , conduil~ Z ~
'~~'pv11 ~ox°
~ ~
s ~ ~ !
1I~~~i ; ~t ~r t
woo r r s w
• A, i s
To s~~yic~ cor~ne~/'ion; I+j ~ ~'°•Ta 1i' h~/~t cir~cwi~` ~ o~ ~ ~ Con~a~t f condvrtar,~ as ~s s~►ocvr~ a~ .~~~rra/
shown on a i9~~/ plan . p/an Id~r~ /'Ifs ~r~r~~~/v~,~d
Gona'va tors ,vu/1 ~ro~.
~r01/11e~ C`d t~°•
•
Ce~r; ~~r of meter sha// 6 r ~ min.
of abavP ~,~ad~ on side
opp~s~fG pd/ica ~nel.
AE'FROY NtE TNB a~Tg ..l~-,G7~
co ~ ~ h~N~~~'~ O
• ARAI~YW
tHEtkED
~ FI£J.~ DQOK
tI.TY tLEAK P~IG~:
~►~g c S~CALL Apf'ROY0~1~ VI` ~~~G.R~~~~~~ n~ SCaIC
~ ~
CtT1P EhIC=•~ ~ ~NGINE~Ri~lG D~P,~R1'~►~~~lT`
m ~ x r~ Q1 N = i
~~J ~ i ~ ~
~ W Q O - a W ~ Q Z
z yo J W ~ cn W 7E N ~ r
<m° J 4. a N-a.
0 • ; J W~o CW7 W ~ZW~ ~ a V O ~ oyJ Z~ W~10:
a zQ ~ Q ~Q W O ~ z = C~ Qla.
D W Z Z ~ ~ ~ ~ ~JZ ~ ~ mJz ~ Z ~ t7 ,r--~ ~ ~ Z 7 Z Q Q'
: 6Q. of y 1 W O Q y ~ 4 V W "c z W ~ I o W 0 i
8~ i > W C7 NCO
„j wee C~ W W ~ 2 = W
Q F.. aW0aW0 ~ J it
O V? N W OJWaU~ 9 ~ x~~0a~ ! N ~ ~ ~ N ~ J ~ Ul Z = W ~ ~~m = W j
a Z N~ O ~oaQJ~ ~ i
> Q ~ ~OZF-jW ~ Q ('1 N i >aNCWa 1 W i
J ~ N
O ~ t~ t9 N ~ 2 _Z
O J t! Z 2 . N Z JW~ yE..aW t
z ~ N I as m4F~ ~~NZ
Y~>W m~ W= a may x~cYi W3z_tW-
Q ~ O m 2 = H O y"~ a J ~ ~ a
N WWUO ~3j ~W~W =c=J i''~-O ~Y J I
I 2;W WJp N~Za I ~ ~ ~ N~~ Zm~F' ~Q.~ WtL Y W
x 3Z2U =tAU Q
( ~ x Nf 1
1 ~a ~
r
~
e_ ..s re
r I~_ ~ j !
1 I
_ ~ ~ .._J ~
►1 . ~ c~
i i ' J ~
h> > W~.~ i \ ~ ~ J W N W O r a j H
f.Q Z W HQ W X~Y ~ 3 ~
~W~ ~~g a
imp =3~ Q NOW N~O V W
J . 0 ~ ~ N Z N
~ ~ et o x 'M® x J
~ ~ ~ J~ ~ i
z ~ '
i i i ~ 3 = i ("t"_¢' ~ j Z ~ ~ ~ I
~ I !!1 W
O N
J
W 2 a ~
z
~ Q C7 i
4: J ~ i E ~ F-
Z;
J W
oaaaaaaQ - Z ~W WWWWW W W O ~ O N N T N N ~ (n ~Z~i
a ~ a ~ zWJ ~~o,
' ~ Z W Q J U W M J~;
2 2 Y O. N Q 1Y ~ y N W~ Q~~ m Qv~: W Z N~Q~OWx, i O W,
~ Q ~za~y~~•~ ~ Z Q J W a~ Q 2 W m x x x p - Z
W ~ y QJaJ d a~=~~ Z V Wi N_ O ~ ~
t F° J ~ O Z ' { t
O ~
~ ~ O O O i
ooa H~ ~ J z ~ p o Z
~ c~ Wii~ z m W W N J O W J~ W Q
F'°N~WJ~ N; a J m W
W 2~ 2 N a oo=iaQ
a O,y=F°OW U W } m
J J~ O X y <~>~z3
N W
~ N Mf ~ O Q 2 ~ ~
.Nr N 1 i
~ , ~ i i
i ~w ,l ~
I Q ~ ~
a ~ a W o o Y
M M~ Q ~ i
. ~ c' j J 1 ~
. Q t ~ M i~
(r. ~ ~
- 1 ~ 1 ' '
~ I ,
O
O W ~ Q ~ O N W ~ ~ I ~
• ~ a ~qa o
ca ~ ~
~ b e~~ .~Z
N i Y L~ O
b A • M ~ 1Y es.~r
11~ NI a ~
Q
d ~ ~ i ~ i ~ ~ . . ~ I
• ~ ~ ~I
~ i t . .Y~ I _ i
1
I i y
i
we
PROPOSAL
FOR TRAFFIC SIGNAL SYSTEM ON
AGATE STREET/CASTRO LANE AT
WILSON ROAD
To the City Clerk of the City of Bakersfield:
The undersigned, as bidder, declares that the only persons or parties
interested in this proposal as principals are those named herein; that this pro- posal is made without collusion with. any other person, firm or corporation; that
he has carefully examined the location of the proposed work, the annexed pro-
posed form of contract and the plans therein referred to; and he proposes and
agrees if this proposal is accepted, that he will contract with the City of
Bakersfield, in the prescribed form of contract hereto annexed, to provide all
necessary machinery, tools, apparatus and other means of construction and to do
all the work and furnish all the materials in accordance with the plans and spe-
cifications for the above, filed in the office of the Finance Director of the City of~Bakersfield and as specified in the contract, in the manner and time
therein prescribed, and according to the requirements of the Engineer as therein
set forth, and that he will take in full payment therefor the unit prices or
lump sums set forth. in the following schedule:
In case of a discrepancy between words and figures, the words shall
prevail; and in case of discrepancies between unit prices and totals, the unit
prices shall prevail.
The undersigned further agrees that. in case of default. in executing.
the required contract,, with necessary bonds, within ten (10) days, note including
Sunday, after ha ng received notice that the contract is ready for signature,
the proceeds- of the: check or~ bid bond accompanying- his bid:. shall become the pro-
perty of~ the City of Bakersfield.
Bidder acknowledges, receipt. of the following. addendum:
ITEM. APPROX... ITEM WITH LUMP. SUM PRICE. UNIT.
N0. QUANTITY WRITTEN IN'WORDS PRICE TOTAL
1. Lump Sum Signals and. lighting, complete°
in place, at the lump sum of
Z. b Each, Install signs (mast arm
hanger,. street name sign), at
Each
SIGNED ~ TOTAL $ Bidder
Page 1 of 1
w
a
'1 S 3si ~aq tl `f ~ i~►' J ! ` ~ ~.w~ *V' 4 ~ ~ i • ~ I
~~4t ;1CC~~~~!'~ 1t LaSii ~r cerY.~i~ ~~z:~; '~til~~; JiC~)
~N~~J ALA .~N B~ THESE ~R,ESE~1T5:
That we
as principal, and
as surety,
are held and i'irmly .bound unto tie City of Bakersf field, a body politic and ~:orporate of the State of
~alif ornia, in the sum of dollars
3 to be oai~. to s~,i~ City . for w ~>ch payment a Dell and truly to be made ; we V
jj vied ours°7ves, ~',:?x ^.e'.: S, eYc~llior'S and ~~Ia'i.:ll;"ti 3~:o~'s, :.i~.i~,C'~:5~4; ~ ~~r 3S i~na , c~inily 3I'1C1 severally by ,
a ~ .
~nese pre; ants.
THE C~NI)I~'IC~N t~~F THIS OBLIGATION IS SUCH
Teat if .the .certain proposal, hereunto annexed , to construct certain worl~ and improvements in
the. ~ity of Bakersfield as referred to in the Notice to Contractors attached hereto, is accepted
by the Council of said City and if the above bounden principal, heirs, executors, administrators, suc-
censors and assigns , shall duly enter into and execute a con~r act, to construct said improvements
aforementioned, and shall execute and deliver the two bonds required by law, within ten days not
.including Sunday) from the date of a notice to the above bounden principal, that said contract is ready
for execution, then this obligation shall become null and void, otherwise it shall be and remain in full
force and effect.
IN WITiv'ESS '~IHEREOF, we have hereunto set our hands and se~:ls this _____day
(Seal)
{.Seal}
tSeal}
~ Seal)
h
. ~Scal)
P
Accompall~•ing this proposal ls.........
"ca$hier's checl~," «og (fi'~T1t;E : Ill~ert tll~ ~~~ords "cash )
.fled check'' or "bidder's bond," as~ the case may be), in amount equal to at
least ten ~~rcent of the total of tliP bid. .
The nai~ic~s of all persons interested iii the foreaoiv~ proposal as prin•
cipals are as follows
' If bidder or other interested person is a cor-
~ ~rtcx~t ~o~c~ . oration, state legal name of .cor oration, P P
also names of the president, secretary, treasurer, and manager thereof ; if a
copartnership, state true name of firm, also names of all- individual copart-
ners_composing .firm; if bidder or other interested person is an individual, state f first and last names in f ull.
. ..............................a..............e..................................................................,...............
Licensed in accordance with an act providing for the registration. of
Contractor's License No
SIGN
HERE
. ~ Signature of Bidder
NOTE~Ii bldde~ i• a corporation. the iegat name of the corporation shall De yet lorth above
together wltb th► slgaatute o! .the atliceT or ot!lcers authoN=ed to Biqa controct~ oa bebaii •t the corporatioas t2 bidder is a copattaerahi~, the true aame o! the tirtn shall be set lorttti above
together Nittt the slgaatu:e o! the pas aer or partaer~ authorlted to .Biqa coattoct~ to behal! o! the copartaer~hlp; and li Didder is as iadl~tdual. b!e ~igaature ~haU Ds pldced above. t! rigaalute ~
8y a>a agent, other thtsa ara ol3lcer of a corporattoa of a mesnbet o! a partnership.- a porter o! JlttoraeY tnu't be oa rile v►tth the CItY Clerk of the Clty o! Sakerstield~ prior to openlaq bldi or
submitted with the bid; otberniee. the btd ~Ul be disregarded as' irregular sad uaauthorised.
Business address.........
Place of residence......
Dated .............................................................,19...........
Wb44UUJ
~ ~ ' . _ ~ i ,
;f 7.
• r V ' - i ' i i
. i ~ ;LIST oF; SUB-C4~CTORS
j,
,
. ~ .
A11 persons- or parties submitting a bid ro osal on the ro'
steals m .p P p sect co plete;the following form, setting forth. the name and
the location ~f they mi 11 ~ ~ sho car office of eac u - p h s b,contractor who wi11 perform work... orlabor or .render service to the contractor `
in or about the construction of~the work or rovement i
mp n excess of . one-half of one! percent of prime. contractors total bid and the
poxtion of the • fork which :will be donee b each sub-contractor. Y
This list. is toy be completed and submitted with said bid ro osal, p p
l
The 5ubletting;and.~ubcon~racting Fair Practices Act (Government
Code. Section .41;00 e~- seg. !applies to all contracts exce t .those p for constructi~o~,..improvement or repairs ofstreet or highways,
in~cluding brdges~.and applies to such: contracts as~to the ~ _
portions thereo~~ cowering `street. Ig~tin and:. traffic si nal .
g g Tf a contractnr~ fa~.ls-- to specify a subcontractor for any ortion
p of the- work toy ~e performed, under the: contxact, he shall be deemed
to have agreed that`he is~~ul1~ qualified to perform that ortion P
himself and. than he shall. perform such. portion himself, and he
shall not be permitted ~v sub-contract that ortion of the work exce . p
pt as; autha~lzed by Sects-on 41.09- of the. California; Government 7i
. • t P~sE+ o - _
~ t ~ ,
( ~i t}F I{ • v, 1 'i :w r'i;v S '•`It ~ :_.pf1t 1~4 w ~1:; t S N A t. i.. } 1 yr i. ~n o 1~ DIV` IoN r~- • J ~ FF
o~ ~1~0 ~TCI~ 7 I, ~ ~DaRESS~ ; . ~ - . ~ ~ ~ WOR~~ INVOLVED:` I
. F f . . ~ a ~ ,1
. C ~ pr i ~jF1
- j « i ~ ' r ~I
f` Y ~ 1 - ~.i 777 ` t' -
a. 'k' ~ fit.. irJ f~ ~ ~ '
r ~ I ` ~ z ~ ~ 7 t. i
f , ~ t t4 ~ i . „
ri, ~ 1~ ` a is4•'~ r f ~ ~ r w.; , ~ iii • ~ f y
` - r I„ .v f i
- r i( .r.. ~ 1~ ~ • T f I a ~ 1 . . . ~
- ~ ~ ~ I ~ ~ . , ~ " ~ ~ . , 3.~ i { ~f k,~ ~
' ` ~ I ' ~ ,
C f~~ ,i' 4
• r I ~ - f
i ;
F ~ -
i ` ~ - 4
-.r ~ F Y ~
~ u .r `
a . , ~ S ` _ r ~ s i~ • ~ i v i.. { t F ~ .
b
4
V
L